Fine Line Art Installation - Terms and Conditions

Effective Date: 01/01/2024

By hiring Fine Line Art Installation ("we," "our," "us"), you ("Client") agree to the following Terms and Conditions. These terms outline our mutual responsibilities and protect both parties during the service process.

1. Services

Fine Line Art Installation provides installation and assembly services including, but not limited to, art hanging, TV mounting, custom drapery installation, custom window treatment installation, custom cabinetry installation, and furniture assembly. All services will be performed to the best of our ability and in accordance with industry standards.

2. Pricing and Payment

  • All quotes provided are estimates and subject to change based on additional services, materials, or time required.

  • Full payment is due upon completion of services unless otherwise agreed upon in writing. Late payments may be subject to additional fees.

  • We reserve the right to adjust prices or provide updated quotes if the scope of the project changes.

3. Cancellation and Rescheduling

  • Cancellations or rescheduling must be communicated at least 48 hours in advance.

  • Failure to provide adequate notice may result in a cancellation fee or a rescheduling fee.

  • In case of unforeseen circumstances (e.g., inclement weather, emergencies), we reserve the right to reschedule appointments with proper notice to the client.

4. Client Responsibilities

  • The Client is responsible for ensuring that the installation area is clear of obstacles and that any necessary permissions (such as HOA or building management approvals) have been obtained.

  • Any pre-existing damages to walls, furniture, or other areas must be disclosed prior to the start of the project.

  • The Client must provide accurate measurements and details to ensure proper installations.

5. Liability

  • Fine Line Art Installation is not responsible for any damages caused by faulty or substandard materials provided by the Client (e.g., defective brackets, fasteners, or hardware).

  • While we take all necessary precautions during installations, Fine Line Art Installation is not liable for incidental damages that occur due to pre-existing structural issues in walls, ceilings, or other surfaces.

  • In the event of accidental damage caused by our team, Fine Line Art Installation will make reasonable efforts to repair the damage or compensate the Client, subject to the limits of our insurance coverage.

6. Warranties

  • Fine Line Art Installation guarantees workmanship for a period of 30 days from the completion date of the project. Any issues arising from improper installation within this period will be corrected at no additional charge.

  • This warranty does not cover issues caused by improper use, external forces, or modifications made after installation by individuals not affiliated with Fine Line Art Installation.

7. Third-Party Materials

  • Fine Line Art Installation is not responsible for the performance, durability, or quality of third-party products, hardware, or materials used during installation at the Client's request.

8. Force Majeure

We are not responsible for delays or inability to perform services due to events beyond our control, including but not limited to natural disasters, strikes, accidents, or governmental actions.

9. Indemnification

The Client agrees to indemnify and hold Fine Line Art Installation, its employees, and subcontractors harmless from any claims, liabilities, damages, or costs arising from actions or negligence of the Client or third-party contractors employed by the Client.

10. Dispute Resolution

Any disputes arising under these terms must be resolved through mediation before any legal action is taken. Both parties agree to attempt good faith negotiations to resolve any issues.

11. Amendments

Fine Line Art Installation reserves the right to update or amend these Terms and Conditions at any time, with reasonable notice provided to the Client for any ongoing projects.

12. Governing Law

These Terms and Conditions are governed by the laws of Texas], and any legal action shall take place in the courts of Leander, Texas.

Contact Information

For any questions or concerns regarding these Terms and Conditions, please contact us at:

Fine Line Art Installation
Phone: 512.571.1631
Email: finelineartinstall@gmail.com
Website: finelineartinstall.com